Mears Ltd v Costplan Services (South East) Ltd and others [2019] EWCA Civ 502
A breach of a room size tolerance provision in an agreement for lease does not necessarily give the tenant a right to refuse to complete the lease.
Facts
The tenant (T) entered into an agreement for lease under which the landlord (L) agreed to procure the construction of two blocks of student accommodation. T agreed to take a long lease of the blocks following practical completion of the works.
The agreement prevented L from making any variations to the works which materially affected the size of the rooms. The agreement provided that a size reduction of more than 3% from the sizes shown on the original drawings was deemed material. 56 of the completed rooms were found to be more than 3% smaller than this tolerance level.
T sought a declaration that any failure to meet the 3% tolerance level was a material and substantial breach of the agreement for lease, allowing T to terminate the agreement or prevent the employer’s agent from certifying practical completion under the agreement.
Issue
Did T automatically have a right to terminate the agreement for lease or to prevent the employer’s agent from certifying practical completion under the agreement?Decision
The deemed materiality reference in the agreement for lease determined whether there was a breach of contract in the first place, not whether that breach itself was material. As a material breach would allow the tenant to terminate the agreement (known as a repudiatory breach) or object to the issue of a practical completion certificate, it would not make commercial sense if any breach of the agreed size tolerance level (e.g. an undersized bin store) automatically had such an effect.Points to note/consider
- T will be entitled to damages from L for breach of contract and will not necessarily be obliged to complete the long lease. Although the Court of Appeal ruled that not every breach of the room size tolerance provision was material, that did not mean that the breaches in this case were not material or repudiatory (that was a question of fact to be decided on another day).
- The Court of Appeal did acknowledge that parties to a contract can agree that a breach of a particular clause will amount to a material breach (it was just that L and T had not done so here). What this case does show therefore is that if a tenant does not want to have to complete its lease if a particular obligation in an agreement for lease is breached, it is important to provide expressly for this in the agreement.
- As is usually the case, the concept of practical completion was not defined in the agreement for lease. This case is therefore interesting for Coulson LJ’s comments on the meaning of practical completion. In particular:
- practical completion is a state of affairs in which works have been completed, free from patent defects, other than trifling ones that can be ignored;
- it is easier to recognise than define;
- there is no difference with patent defects between an item of work which is outstanding and an item of defective work which requires to be remedied (snagging lists can cover both);
- whether or not a defect is trifling is a matter of fact and degree and just because students could live in the property did not necessarily mean that the property was practically complete; and
- the fact that a defect is irremediable (as in this case) does not of itself prevent practical completion.
Contact

David Harris
Professional Development Lawyer
david.harris@brownejacobson.com
+44 (0)115 934 2019
Related expertise
You may be interested in...
Published Article
Kick-starting the UK hydrogen economy
Legal Update
Higher-risk buildings – are you ready for 30 September 2023?
Published Article
Amendments to Procurement Bill: Navigating sanctions and supplier bans and impact on the construction sector
Legal Update
Solar panel projects for higher education institutions
Legal Update
J A Ball Limited (in Administration) v St Philips Homes (Courthaulds) Ltd
Guide
Government response to the consultation on the Higher-Risk Buildings Regulations
Published Article
What are freeports and what benefits could they offer?
Guide
2023: Horizon scanning in construction
Opinion
Logistics firm fined for multiple failings leading to asbestos exposure
Logistics company Eddie Stobart has been fined £133,000, after a series of failures which took place whilst excavation work was carried out, exposing its staff to asbestos.
Legal Update
Improving the performance of the NSIP planning process and supporting local authorities
Press Release
Browne Jacobson advise CTS Group on latest geotechnical consultancy leader acquisition
Browne Jacobson’s private equity (PE) dealmakers have advised Palatine Private Equity backed CTS Group (Construction Testing Solutions Limited) on its latest acquisition of Concept Engineering Consultants Limited, a leader in geotechnical, structural and geo-environmental services for an undisclosed amount.
Published Article
Rolls Royce SMR ambitions will bring Hinkley like benefits to regions
Rolls-Royce has shortlisted six locations for its first factory for small nuclear power stations. We look at the impact on regions & local businesses
Published Article
RAAC planks and its impact on local authorities
Recent reports of flat roofs constructed using RAAC planks collapsing without warning prompted the SCOSS alert.
Guide
How will the Building Safety Act 2022 impact buildings completed before the Act comes into force?
Guide
How will the Building Safety Act 2022 impact on the design and construction of buildings commenced after the Act comes into force?
Guide
How will the Building Safety Act 2022 impact on the ownership and occupation of higher-risk buildings?
Published Article
The Building Safety Act 2022: Navigating building liability orders
Opinion
Compliance - small businesses and new regulation
The Federation of Small Businesses (FSB) has released a report setting out the impact of new and changing regulations arising from the pandemic on small businesses across the UK.
Legal Update
Construction: Gold Standard Framework – seven months on
We have created a summary of the recommendations and consistent themes which we are now starting to see becoming more embedded in public sector procurement practices.
Published Article
Sustainability in construction
The climate emergency has reached a point where real and substantial damage is being caused to both the planet and society. There has been a shift from planning and theorising the most effective solutions, to a phase where practical, efficient, and sustainable solutions are required at speed.
Opinion
Responding to Grenfell – Slow progress is better than none
As the Grenfell Inquiry continues, how have the Phase 1 recommendations changed the fire safety and building safety landscape?
Press Release
Browne Jacobson advises Charterpoint on sale of 73-bed care home site
Browne Jacobson has successfully advised Nottingham based developer Charterpoint on the sale of a 1.2 acre care home development site in Thurnby (Leicestershire) to care home operator Cinnamon.
Opinion
Building Safety Bill receives Royal Assent
The new regime introduced by the Act will take shape over the next 18 months, but those who design, build or manage high rise buildings are being urged to get ready for the changes to be introduced through the act.
Opinion
Update: building safety repairs pledge signed by over 35 major housing developers
On 14 February 2022, Secretary of State of the Department for Levelling Up, Housing and Communities, Michael Gove, announced proposals designed to pressure building developers and materials manufacturers to fund the remediation of unsafe properties.
Press Release
Browne Jacobson broadens its construction offering with appointment of nuclear and renewable energy specialist
Browne Jacobson has broadened its national construction and engineering offering with the appointment of construction partner Zoe Stollard into its Birmingham office.
Opinion
HSE Campaign Targets Construction Industry in Birmingham
The HSE has announced a campaign targeting health and safety in the construction industry in Birmingham. The Campaign is in response to a significant increase in development across the city, partly as a result of preparations for the 2022 Commonwealth Games.
Opinion
Are whistleblowers entitled to keep their employer’s confidential documents?
In Nissan v Passi, the High Court recently considered the issue of an employee retaining confidential documents belonging to his former employer in the context of the employer’s application for an injunction seeking the return of such documents from the employee.
On-Demand
Levelling up white paper strategic briefing
The levelling up white paper sets out a set of 12 priority ‘missions’ to be pursued by national and local government in the years to come. With measures covering regeneration, communities, connectivity, education, R&D, employment, and health.
Guide
2022: Horizon scanning in construction
Published Article
Construction needs to do more to reduce carbon emissions
More needs to be made of these procurement routes, with clients honouring the original concept rather than watering down concepts.
Legal Update
Have You Gotta Have Faith? The effect of good faith and mutual co-operation provisions in construction contracts
In this article we explore the concept of good faith in the context of construction contracts for public bodies, and what the recent decision in Van Oord Ltd v Dragados Ltd does for this area of law.
Legal Update
Using building contracts to go ‘green’ in health buildings
With the COP26 summit which was held in Glasgow in November 2021 and the increasing global awareness of environmental concerns, the world of construction cannot escape the shift to operating in a more sustainable manner.
Press Release
Firm expands construction practice into Manchester with key legal appointment
Browne Jacobson has appointed Ragene Raithatha, a specialist in both contentious and non-contentious matters, as a Legal Director in its new Manchester construction practice.
Published Article
The future of building
Construction is a major contributor to carbon emissions – buildings consume 36% of energy produced globally and are responsible for 39% of carbon emissions.
Legal Update
The Building Safety Bill – what does it mean for you?
Earlier this month the Government published the Building Safety Bill as part of its continuing efforts to respond to the Grenfell disaster and recommendations made following the Independent Review of Building Regulations and Fire Safety led by Dame Judith Hackitt.
Published Article
Procurement reform: what’s in it for construction?
The consultation Green Paper: Transforming public procurement was issued by the Cabinet Office in December 2020. Whilst we await the Bill, the Green Paper sets a very strong direction of travel and there is much to consider for the construction sector.
Legal Update
Early contractor involvement is growing in popularity with local authorities, but which is the best route, JCT or NEC?
Joint Contracts Tribunal (JCT) and New Engineering Contract (NEC) - which drafting works best, and where are the traps for the unwary?
Training
Regeneration review - where are we now?
Catch up on our regeneration video, where we look at four keys areas of regeneration; public law, planning, construction and real estate.
Legal Update
Bernel Ltd v Canal and River Trust [2021] EWHC 16 (Ch)
A developer was unable on the facts to establish a right to drain onto its neighbour’s land without permission.
Training
Private sector development club - 3 February 2021
Catch up on our Private Sector Development Club on-demand video where we covered a variety of topics including managing construction projects during a global pandemic, tax and planning.